Claims Consultancy

[claimsconsultancy-blog]

How to handle construction delays in residential projects

As the opportunities for business and trade in the Emirates bloom, the residential sector is also expanding to accommodate the growing workforce. Increase in the pace of development projects comes with the increasing possibility of delay claims.

Whether it's a commercial, industrial, or residential project, it's impossible to steer clear of delays. Delays are unavoidable in the case of construction objects, mainly because of the many parties involved in the execution of the residential projects. The rightful resolution of which requires expert witnesses.

Resolution and handling of claims regardless of whether parties are defending or creating claims require the help of these experts. Opt for delay experts to help out with the delayed handling for a more effective resolution. The article highlights how residential project delay claims can be handled.

How to handle residential project construction delays

Being aware of activities at the project site is essential. Not only is it essential to observe the delayed activities but also the causes that have resulted in claims. Completion of documentation and the assessment and handling of the damages play a huge role in handling delay claims. Read on to know the details:

Stay vigilant about delays

When on the lookout for delays, it's essential to stay attentive towards the causes that may result in claims. The causes for the claims may be numerous and of various types. Natural causes like poor weather may be few; however, causes linked to resources may be abundant in number.  

Poor planning or delays in supplies are a few such causes that may cause delays in the construction of residential projects. Ignoring the first few schedule issues may result in serious mistakes, since any demands for time extensions need to be addressed immediately.

Moreover, being vigilant about delays and addressing them as soon as possible remains the most appropriate way to mitigate damage.

Complete your documentation

After initiation of the project, it's essential to be careful about any delays encountered and maintain any supporting documents relevant to the activities that will be affected. In addition the updates to the schedule should be recorded.  Other costs to be recorded and updated include:

·         the recorded schedule

·         the costs recorded

·         the impact of delay on activities

·         Efficiency and workload of labor.

It's important to note here, that out of the conflicting entities, the one that maintains the most comprehensive records for any changes tend to be more successful in winning residential construction delay claims.

Be mindful of damages

In the case that the actual damages are hard to ascertain in the case of residential projects, construction contracts use liquidated damages. When using liquidated damages, contracts award a certain sum every day past the planned completion date.

Tried and tested methodologies like the Critical Path Method is used to ascertain other forms of costs. In the case that the liquidated damages have not been mentioned, actual damages need to be determined. Owner inflicted actual damages may include the following:

·         Lost rents

·         Lost profits

·         Insurance costs

·         Overheads

Contractor inflicted delay damages may include:

·         General extended conditions

·         Rent of equipment

·         The maintenance cost of equipment

·         The increased cost of materials

Conclusion:

When it comes to defending claims delay claims.  It's critical for entities to anticipate the problems the project may face, the resulting impact and the activities that will be impacted, and any adjustments to align the project to minimize delays.

To create claims, on the other hand, it's critical to be prepared, document any causes and shift claims to the other party by drafting a contract as such.

For error-free claims handling of the residential construction projects, it’s essential to acquire the services of the best delay experts. With the right expertise, there is no going wrong with handling claims for construction projects.

[claimsconsultancy-blog]

Three Steps To Dispute Resolution In Construction Industry!

Construction projects in the UAE can see multiple disputes before the final project delivery phase. And, these disputes must be resolved adequately and promptly to avoid causing harmful impacts on your project in particular and your company in general.

However, the dispute resolution process in construction involves several steps that start with negotiation, includes mediation and end at arbitration or litigation. Thus, contracting parties naturally start off the process with less expensive and more casual ways before resorting to more significant commitments of money and resources.

But, employing competent quantum expert at the early step of dispute resolution in construction projects is very favorable as they can provide you with expert technical advice in the context of disagreements.

Thus, you will have an effective and economical resolution at the end either employing supporting resolutions or by assisting your legal team in the formal dispute resolution procedure in construction.

Dispute Resolution Methods in Construction

Here we have explained the three dispute resolution methods in construction that will give you valuable insight into the critical phases of resolving disagreements:

Mediation

Mediation is the first and somewhat an informal form of dispute resolution mechanism in construction. Here the neutral third party helps the conflicting parties to reach a consensus. Instead of imposing a solution it employs the services of a professional mediator to find out the possibilities of intersects.

This procedure permits the parties to share their grievances and communicate their feelings while finding out the potential for harmonization.

Thus, professionals sometimes work together with the contracting parties and sometimes distinctly to find out a potential way out that is sustainable and voluntary. But, it is nonbinding for the contracting parties.

Read to know some interesting misconceptions and workarounds of mediation procedure.

Arbitration

One of the dispute resolution steps is arbitration that involves a neutral third party such as a quantum expert that acts as a judge and has the crucial role in resolving the disagreement.

He listens to each party when they argue their case and gives supportive evidence. And afterwards, he renders a decision that is binding upon each party. The conflicting parties can negotiate on any element of arbitration process involving the presence of lawyers or the standards of evidence employed.

One of the many advantages associated with arbitration is that it is relatively a cheaper process when compared to litigation.

Litigation

The most distinguished mean of dispute resolution in construction industry is litigation. It generally involves a defendant that faces of a lawsuit before either a jury or judge.

The judge has the crucial role in weighing all available evidence and rule accordingly.

Lawyers typically dominate this dispute resolution process in construction and often influence settlement agreement between the disputants even during the pretrial phase of the legal process.

Typing it All Together!

Construction is a risky venture in the United Arab Emirates because of many unforeseen incidents that can have a considerable impact on your project schedule and budgetary estimation. Thus, disputes resulting from time and cost overruns are very usual in these ventures.  

Here, the role of quantum expert in dispute resolution procedure in construction stands paramount. They not only provide expert advice on all conflicts but also support your legal team if you have opted for litigation as a dispute resolution method in construction industry.

Watch This Out!

[claimsconsultancy-blog]

How Can Professional Claims Consultants Save You From Risks?

Consultation generally refers to seeking an opinion or advice of experts for making a decision.

The same holds true for construction claims. Consultants here also improve the quality of your decisions and, as a result, your business profitability and viability enhances.

These experts have a key role in identifying, analyzing and responding to risks in your construction projects.  

They are specialized and have a thorough knowledge of construction projects and civil engineering.  

As they know every in and out of the construction industry, they can save you from any liability before it starts.

Discussed below are some of the attributes of the construction claims consultants Dubai that save your project in particular and company in general from risks:

They Have Legal Insight

Improper understanding of the claim can cost you much both in money and time. Thus, you must be working with the experts who have a legal insight and help you understand the exact nature of the claim.

They have years of working experience. Therefore, they can manage the issue before it creates a legal problem for your company.

Still, if you have got a legal issue, these experts will use every detail to strengthen your case.  As they are highly knowledgeable, they can analyze potential mistakes in your construction project.

They also have the potential to analyze cases of negligence. And their analysis has a substantial impact on your legal standing.

This is the most vital role associated with this team of experts.

They Are Your Potential Savior

They have a crucial role to save your project from risks which is vital for your business’ safety. They keep an eye on problems and weak areas in your construction project.

Moreover, they expect issues before project managers even notice them.

Thus, they protect your firm by preventing issues from brewing up.

Therefore, hiring construction claims consultants Dubai to analyze your project’s health can save you from serious problems arising in the later phases of project management.

They are Expert Negotiators

When disputes arise in a construction project, only a good negotiator can rescue you. Conciliation plays a vital role in disputes management.

Therefore, an expert negotiator will give the best resolution to a complicated dispute by maintaining a win-win situation for all stakeholders.

Can Handle All Types Of Claims

In the construction industry, claims are of a diverse nature. A skilled professional has an insight into the legal matters and is capable of analyzing any claim coming in your way.

He not only performs proper analysis by employing appropriate project management tools but also helps you to respond adequately.

Thus, saves both your money and time.

Has Latest Updates In Changing Standards

Regulations are continuously changing in the construction industry. And, if you are unaware of these most recent standards, you might be at a loss.

Expert consultants always keep track of these evolutions in the industry and thus save your project from risks by updating you on the latest standards.

Final Words!

Simply put, construction is a very volatile business in the United Arab Emirates. It involves risks on multiple fronts, therefore, seeking for the services of professional construction claims consultants Dubai save your construction project in particular and your business in general.

[claimsconsultancy-blog]

How to Perform Delay Analysis without Project Schedule

Construction sector in Dubai often suffers from delays due to different reasons. For instance, poor weather, budget shortage, unskilled labor, and unexpected contractual changes. Some of these causes are excusable and some of them are inexcusable.

Furthermore, construction delays create many issues for the companies. For example, the firms need to employ more resources, invest more money and wait for longer than scheduled for the completion of a project.

And delays can even cause the conflicting party to file claims. Once a petition (claim) is filed, the company needs to perform the delay analysis to compensate for the alleged loss caused by project delays.

Under these circumstances, companies need the services of experts to help them perform the delay analysis effectively. Without it, complications in the project can arise, escalating the loss estimates.

Hence, first things first, hire the services of the best delay expert in Dubai to ensure effective handling of the highly intricate matters such as construction delays. Read on to know expert tips on performing the delay analysis without a project schedule.

Steps to Perform Delay Analysis without a Project Schedule

Performing delay analysis is a technical procedure that is based on concrete proofs like project schedules etc. However, claimants sometimes, fail to offer regular project schedules and updates which makes the analysis more complicated. Here are the steps to perform the analysis with no plan.

Identify Useful Sources

Without a project schedule, you need to construct the model (baseline) schedule for your analysis. So, the first step is to identify the available sources that you can use. For instance, check daily reports, minutes of contractor meetings, bids, and other relevant documents.

Moreover, identify the key people in the project. Subcontractors, engineers, architects and project team members are some of the key stakeholders in construction projects. Schedule interviews with these key stakeholders to get relevant information.

Make Initial Plan

Once you identified the vital resources of a project, interviewed the chief stakeholders and collected all the essential documents. It is time to establish your ‘Schedule Basis memorandum’. It is an informal project plan that helps to provide the outline for the baseline schedule. It also helps to know the project developments and updates.

List the Assumptions

In this step, make a list of your assumptions about the conditions of the project. Document your findings and reconsider and refine them continuously. Now collect budget details, expenditures and resource plans and analyze these details.

The new findings will help to transform your initial assumptions into prefatory schedule basis memorandum. It should contain all the schedule content and work breakdown details.

Inspect Project Activities

Now, review all the data and resources to analyze all the project activities. Then, match these activities to define their relationships with the job responsibilities of the workforce and stakeholders.

Reconstruct schedule updates and compare it with the initial one to determine the beginning of delays. Use the sources again to recognize delay-causing circumstances. Now meet the stakeholders again to authenticate the findings. Now include the delay-causing events into the schedule, separately.

Bottom Line

It is a significant challenge to analyze a project delay without having a schedule. But an expert can overcome this obstacle by using the steps mentioned above. A quick tip is to perform an initial review to determine the intricacy of a project.

Moreover, hire a professional delay expert to minimize the risks and maximize high-quality results. A professional will help to make the process all worthwhile.

[claimsconsultancy-blog]

Top reasons site visit can reduce the chance of delays

The construction industry has broadened its horizon over the years and if you think that the number of buildings is increasing every year. There are more residential areas and shopping malls than there were ten years ago.

But one thing in the construction industry has not changed despite the recent development and advancements, and that is construction delays. A project might have a timeline of six months, but it might be in the initial phases even after one year. This is because there are mistakes and loopholes either from the manager or owner side. Delays not only result in increased use of resources but waste a lot of time which can be used in other projects effectively.

One of the common reason for delays is that the site is not ready for construction. Often managers and contractors don't think about site visits before they plan the timeline and sign a contract. But once they reach the place they understand it requires time to make the site ready for construction. The delay in that situation will become a claim which will put the entire project on hold. If you are in that situation and require expert advice, then services of delay expert should be able to serve the need.  This article is going to share reasons site visits can reduce the delays in the projects.

Reasons site visits before the project will reduce construction delays:

Often when the construction project starts then, managers usually don’t understand the need of visiting the site which is a big mistake.  The land should be ready for construction before the planning process begins because then it will take the whole project on the estimated time.

Following are some of the reason the project can be completed on time if the manager visits the site before starting:

Get a first-hand understanding:

When you are signing up for a project, then you need to have a firsthand understanding of the land, its situation and if it requires any maintenance. For example, the owner might say that land is ready for construction, but it is the contractor who will check if it is actually ready or needs some work on it. If the contractor will just believe the owner then later found out that it actually requires some work then it will result in a delay.

Provide the right guidance to the team:

When the manager is aware of the site, then he or she will be able to guide regarding the project and how to go about it. The advice and assistance will put the entire team on track, and nothing will be wasted in terms of time and resources. However, if the manager is not aware, then the team will work what they understand, and the interpretation can go wrong.

Match the timeline with the work:

This is the most important reason for visiting the site before the construction project. You might have prepared the time frame for the project, but when you visit the site, then you will be able to understand whether it is right or not. By right mean that time and budget you have estimated should align with the actual work you can see by checking the site.

Final thoughts:

Delays often occur because the concept of site visiting is often overlooked. If you are stuck in such an issue where not visiting a site caused you a claim then the services of delay expert will solve your problem. But if you are starting the project, then these reasons should be able to convince you to visit the site at least once.

[claimsconsultancy-blog]

Performing Effective Claims Analysis For Schedule Delays

The study and delay claims analysis of the construction industry can be as complex and confusing as the processes involved in the construction industry themselves. The involvement of multiple parties in the claims process makes it all the more complicated.

The growth of the UAE has also brought forward the need for construction processes to develop the landscape and to accommodate entities.  Naturally, construction claims are also an essential part of construction operations in the area.

Despite the complexity of the claims, the right construction claim consultants Dubai can help you resolve issues via comprehensive claims analysis. Whether the resolution is inside the court or outside, the most experienced people in the industry have the required knowledge to resolve conflicts and to maintain your business relations. The following article aims to highlight how the claims analysis methodology follows a schedule delay.

Here’s How to Perform Schedule Delay Claims Analysis

Similar to the complicated nature of construction claims, the resolution cannot be a three-step easy procedure. It requires extensive research and analysis, derivations and the determination of results and conclusions. Experts perform a comprehensive study before they eventually resolve any claim issues:

Acquire And Analyze Files

The first step in delay claims analysis involves the collection of all native electronic files including baseline, schedule baseline, rebase line (if any) and any periodic updates. Once the files have been acquired it’s essential to look for any logic errors in the schedule or if there are a high number of constraints governing the schedule.

It's also important to find out if the “as-planned” schedule prepared by the contractor is logical. The entire scope of work needs consideration with the “as-planned” schedule.

Identification Of Critical Features

Once the analysis is complete, claim expert’s analysis the number of time extension requests sent along with those granted need to be identified. These requests are due to approved and pending change orders.

Also identify any acceleration attempt to compensate for problems causing delays, along with the nature of acceleration whether directed or not.

Determination Of Dates

In case the contractors planned to finish the project work at an earlier date determine what methods they used to determine the date and how the owner go to know about it. As-built start and finish dates for any scheduled activities are also determined.

Identification Of Milestones

Identification of relevant milestones and any specific periods remains a critical aspect of delay claims analysis as it allows the calculation of other essential factors such as liquidated damages and any time-related costs of the team involved.

Method For Schedule Delay Claims Analysis

Use industry standards to determine the method for schedule delay analysis to be used based on industry practices and standards. Once identified,   it is important to determine any windows or a specific time for which there is a need for delay assessment.   In case there is a need, the schedules need correction before the implementation of delay analysis.

Certain delay claims analysis methodologies incorporate Activity durations and relationship variance to allow quantification of delays start and duration. Perform calculation of variance tables for the different time periods.  

Division of delays to activities mentioned in the above tables (variance table mentioned above) leads to the determination of responsibilities for the delay. Use claim Issue analysis and acquire services of legal counsels if needed. Any large delays that have not in the claim Issue analyses should be described.

Identification of actual and planned start dates, milestone activity durations, completion dates, and all activities on critical and non-critical path follows.

Figure out if the as-built and as–planned critical paths are different for a different period of the analyses along with any delay or problems a result of the delay. Determine where the work affected by the event lies? On the as-planned or the as–stated critical path (at the time of occurrence).

Determine concurrent delays

Identify any delays before or after the occurrence of the problem and any unrelated delays that happened to be specific to each problem’s time frame. Was the work out of sequence with the “as planned schedule”?

Compensable delays

Determine any delays related to different site conditions, delay in work, bad weather or any issues there have been no time extensions requests or grants.

Construct "Fragnets."

Using claim issue analysis constructs a fragnet; a compilation of schedule activities inserted into the schedule itself to represent delaying events. Use the fragnet to determine which delay activities are being affected.

Retrospective Schedule Analysis For The Extension, Delay, And Costs

Determine using a retrospective schedule delay claims analysis such as Time Impact to determine how worthy the contractor was of a time extension. A method considering an appropriate methodology is used to assess whether compensation for time, cost and extension is possible.

Determine unpaid acceleration costs, via results of a retrospective schedule analysis which determines any relevant accelerated work. Liquidation or any actual damages due to delay need to be determined too.

Prepare Narratives

Create narratives with relevant supporting documents that allow you to present the information used. Any problems faced, analysis performed and finally the results and conclusions need to record in the narratives.

Conclusion

Owing to the comprehensive nature of claims analysis and the importance of conducting an effective claims analysis it’s essential to acquire the services of the best construction claim consultants Dubai.  Any Professionals in the industry with numerous years of experience have expertise in relevant fields and can provide you with comprehensive delay claims analysis and resolution services.

[claimsconsultancy-blog]

Provision Of Evidence In Arbitration Proceedings By The Expert Witness

Contractors must keep in mind that the claimant carries the legal burden of proof claims, asserted have to be fortified up to certain required standards. The primary objective is to explain to the arbitral tribunal that all losses claimed are reasonably likely to have occurred.

To allow complicated assumptions, needing quantification in the reports generated, the counsel and experts interpret causation and liability to have been established.  

Regardless, construction claims remain laden with evidence, and it’s reasonable to expect a large amount of documentation to appear, as evidence in arbitration proceedings to the claims. Construction projects and claims provide comprehensive paperwork; from planning to procurement from variations and monitoring to completion and accounting to be studied by expert witnesses.

Hire the most well reputed, quantum expert to help out with construction claims, and your arbitrations are going to go in your favour!

Expert Witness’s Role in Providing Evidence in Arbitration Proceedings

In all cases, all documents that have been filed to support the calculations of claims should possess three features, and they should be sufficient, relevant and reliable. Spreadsheet summaries that are produced by the contractor’s staff may be incomplete and not fulfilling the criteria.  

To prevent this, the expert witness should consult contract to determine the forms of proofs required in disputes. The expert may determine whether the provided evidence in arbitration proceedings is sufficient or not and the arbitral tribunal ensures findings on issues pertaining to evidence.  

In some cases, for evidence that is sufficient, it’s important to disclose and identify all the documents regardless of the format they are in that could be expected have been prepared with the purpose of authorising or supporting legal or financial transaction. Or support legal or financial exchanges.

The Evidence In Arbitration Should Be:

Contemporaneous

Generated by the third party

A separately identified document

Relevant

Original

Translated suitably into the terminologies use by proceedings

The evidence provided should make sense and support any point made, data being used and the report provided by the expert by the expert. Contemporaneous evidence refers to the collection of data at the time of the activity and not in contemplation of any dispute.

The arbitral tribunal requires contractors to provide proof of head of claim by reference to the contemporaneous and relevant evidence in arbitration proceedings.  

In order to support the monetary value of each claim, contractors should be prepared to give out a detailed record of the costs that can be implemented to relevant tasks events or a period.  Level of details requested by the employer may appear to be extremely challenging to the contractor.

When responding to such requests, the first challenge encountered is the identification of the document or record that would be supporting the asserted amount, and to ensure that the request in the evidence is covered. But this is easier said than done.

Importance Of Project Documentation

A formal, comprehensive system that involves accounting, technician project management documentation is developed to ensure accurate execution of the project, which is according to the budget and time. The quantum expert, however, considers these documents and essential foundation methodologies and calculation can be built upon.

Once identified, the expert witness their legal team and the contractor needs to collect and organise necessary records and evidence in arbitration proceedings that support the amount that has been claimed. The organisation requires a document management system that included hard copies and soft copies. Numerous firms provide secure premises for their clients to store data.

Takeaway!

Arbitration proceedings are comprehensive discussions that the clients are often satisfied to perform. Despite the many challenges faced by experts during the arbitration proceedings, Opt for the best expert witnesses for a peaceful, systematic resolution to construction claims.

[claimsconsultancy-blog]

Disadvantages, Misconceptions, And Workarounds Of Mediation Proceedings

The UAE sees 11.0 % of construction claims getting resolved using mediation and very few cases make it to litigation in court. Negotiation and mediation make up a large percentage of out of court settlements for construction claims.

Mediation in construction claims requires a consensus of both parties to be carried out. The third party also termed the mediator works with the two disputing parties to explore the problems and to help them reach a decision that not only out of court but one that's beneficial for both parties.

In doing so, the mediator works towards a “Win-Win” situation for both parties which is implemented in the case of acceptance by both parties.

Mediation proceeding may have numerous advantages including:

Saving cost, time and effort

High level of confidentiality

Its ability to facilitate communication between parties

Unbiased coverage of the interests of parties and more

But just like any other method to resolve disputes, it has disadvantages too which will be discussed later.

Regardless of the type of dispute resolution process that the disputing parties decide on, it is of primary importance to hire the best, most well reputed and experienced construction claims consultants to work with the parties to assess their needs, their issues to come up with a solution that's best for both parties.

Disadvantages And Workarounds Of Mediation Proceedings

Mediation for construction claims have disadvantages which can be minimized as discussed in the following article

A) Enforceability May Be An Issue

Due to the nonbinding nature of mediations, they may be non-conclusive, which may make it a significant concern for the parties involved and who assume their case is strong. Since both parties involved tend to feel, they did a good job at being righteous, and both of them need a strong case to win. Which is why the parties often feel mediations are useless.

However, some construction professionals feel, mediation should be the default method for alternate dispute resolution because arbitration can lead to a decision that needs to be enforced.  

In the case of a settlement between the two disputing parties, mediators will provide both disputing parties a "WPMA –without prejudice mediation agreement” which the parties will willingly sign.  Since the agreement does not bind them legally, they are allowed to consult experts independently to obtain legal advice.

Once reviewed the parties will be given the “mediation agreement” which both parties need to sign which goes in to form the legally binding contract for the two mediating parties. The procedure ensures that the mediation agreement is enforced.

B) Mediation Means Compromising

A common misconception among disputing parties considers meditation as a compromise between the disputing parties. Not only is this a huge, misconception but it tends to underestimate the power of mediation.  And its ability to facilitate communication between the disputing parties.

Mediators, in reality, are not biased against any of the parties and do not possess the authority or the ability to get either party to compromise or enforce compromise upon either of the parties. The misconception is a major reason why knowledge regarding mediation is required, i.e. to clear out common misconceptions regarding the process.  

Accreditation, certifications and continuous professional growth are important aspects to ensure that the mediators are competent to perform mediation activities.  

C) The Unwillingness Of The Public Sector

The officials in public sector may not be willing to settle for something they will later be made accountable for and the representatives of the party, in the case they are government officers, do not have the command to settle disputes.

These are some of the main reasons that disputes between contractors and government clients do not result in mediations and aren’t a common sight. Despite the lack of mediations in the government projects, it is desirable that any government parties enter the process of mediation, in order to achieve partial settlement of some of the disputes and leaving the rest to be resolved by other methods such as adjudication. This is one of the reasons, mediation clauses in work contracts are considered extremely important.  

Conclusion

The combination or individual disadvantages associated with mediation and the misconceptions about the process limit the industry-wide application by professionals in the construction industry. The disadvantage may be overcome using suitable practices and alteration to help parties better understand what the mediation process is about.

It’s essential for disputing parties to opt for experienced expert from construction claims consulting firms who can explain to the parties, the importance and the ability of the process to resolve disputes without destroying professional relationships between clients.

[claimsconsultancy-blog]

Helpful Tips For Adjudications In Delay Claims

Adjudication refers to a compulsory mechanism for dispute resolution using which an arbitrator or an adjudicator review evidence and arguments along with legal reasoning presented by both parties in order to reach a decision which will determine the rights and obligations between parties.

Construction disputes are highly reliant on expert consultation and evidence. Clients often need experts to work with them to determine what may have gone wrong.  And many parties also use their help before opting for court proceedings. Delay experts may be referred to, in the case of construction delays in order to help out with the construction claims more uniformly and consistently.

Delay Claim Adjudication Tips

The following text aims to highlight useful tips which both the referral and the respondent parties can use in order to provide a sustainable case in the delay claim adjudication proceedings.

Tips For The Referring Party

The referring party that is claiming an extension of time should:

Provide an explanation for the delay events using accompanying evidence. The inability to present a set of evidence will not be persuaded to grant an extension, even consider the option, in the presence of only the as-built and as-planned program without any pieces of evidence.

The explanation of the delay events should be:

Presented in the narrative of the referee or in the witness statement, and a member of the team that has been on-site and is well aware of the specifics of the project. Entities and parties that are disconnected from the actual aspects of the project and have minimal knowledge should not be acquired for the explanation.

The explanations of the delay events will be cross-referenced to the comprehensive evidence provided including all the plans and minutes of meetings. Even photographs provided by the teams can hold great importance in the delay claim adjudication sessions since the adjudicator may not have visited the site himself.

The delay events to be discussed must include those that caused a critical delay. This refers to the events which led to a delay in the completion of the project, extending the completion date beyond the initially planned completion date.

Most parties include delay events which may have delayed the project, however; they aren’t critical delays which waste the time of all parties involved.

The evidence provided with the delay analysis should be used, wherever necessary. For mega projects, it remains  an essential piece of the puzzle when demonstrating critical delays to adjudicator experts

Importance of the right expert and the right technique for delay analysis

Your choice of experts should be able to convey to the adjudicator, their competency and capability in the matters of delay. He should be aware of the essentials of project planning, which is why it is essential to choose an entity that has multiple years of experience in the industry and certifications that certify his knowledge and his abilities.

The inability of your party to present an expert in front of the adjudicator conveys that their competencies are merely limited to the use of delay analysis software.

The party claiming to be the expert should be an employee of one of the parties. However, they should be well aware of their duties in the delay claim adjudication process, of maintaining an unbiased meticulous approach towards the scenario.

The technique implemented depends mostly on the evidence that is available.  For instance, in the absence of an as planned program, other techniques will have to be used.

Test the submitted documents and evidence. Although the idea may seem a little impractical, it is always better to hire an experienced adjudicator to review claims before they are submitted to get an overview of the documents.

Tips For The Responding Party

Some of the tips that have been mentioned above may apply to responding parties that are defending extension of time claims in the adjudication sessions; however, some specific tips for the respondent include:

Progressing with a positive case when replying to delay claims. Although the offensive approach which is limited to attacking the delay claims and the reasons that the referring party gives in its defense is preferable, however, the defensive approach may help out a lot too.   Respondents can refer to the actual situations that caused a delay in order to present a positive case in front of the adjudicator.

The respondents should also be using expert delay analysis wherever necessary. Not only this! The responding parties may feel that the use of a different delay tool may provide a more accurate way to analyze delays however it is appreciable for the responding parties to use the same kind of technique for delay analysis as the referring parties.

Respondents shouldn’t rely on the referral party’s lack of evidence pertaining to the expert delay analysis, as their only defense in adjudication since the adjudicator may find that regardless of the lack of expert evidence an extension is due. For instance, for an obvious delay event, a detailed delay analysis may not be required by the adjudicator to reach a decision.

Takeaway

Be it delay claim adjudication, arbitration or mediation; delay experts remain an important aspect of all construction claim disputes. Hiring experts with experience and knowledge about the construction industry can impact positively, the proceedings in the case of in court and court or court settlements.

[claimsconsultancy-blog]

How To Conduct Construction Damages Analysis Using Critical Path Methodology

The industry of construction is flooded with incredibly high paced projects. It is owing to the ever-increasing needs of the people, augmented business investments and technological advancement.

However, it not only augmented the progress but also cause to pressurize the contractors in accomplishing their tasks efficiently but not everything is in the control of contractors or project owners.

Why Are Delays Critical In Construction?

The volatile nature of the construction sectors disrupts projects leading to potential delays. No matter how many sincere efforts you have done to achieve success, there are a few things you cannot control at all.

Delays are the uninvited guests who may visit at any moment, but the grounds are already set for them. The causes may be many, but the most important reason for the delay is the negligence. Small activities and tasks are delayed first and get accumulated to disrupt the construction process altogether.

So, it is essential to stay pro-active and manage everything critically in order to eliminate the probability of procrastination. It is perhaps the reason that many dynamic project managers hire quantum expert during the initial days of construction projects to get proper estimations and analysis reports.

Methods Of Analyzing Delays

Various techniques are used by the experts to analyze delays and disruptions in the on-going or hindered projects. One of these is the Critical Path Method (CPM).

The article is designed to help the readers in understanding how CPM is used to assess the causes of delays and potential ways to eliminate hindrances.  

Critical Path Methodology

The CPM is easy to understand because if you are associated with the industry, you have undoubtedly observed such situations many times.

When a project is delayed, the engaged workforce asks for additional working charges which lead to extra costs. In such a situation the analysis of schedule delay is done. As the part of it, critical path methodology is adopted.

In this way, the CPM is used to determine all factors using an analytical process to perform the forensic review. During the analysis, various points are connected by examining relevant data and documents are prepared.

How To Conduct CPM

The following are the steps required to conduct critical path methodology for a delayed project:

Analysis of the work plan is done thoroughly in order to estimate the intentions, project nature, potential delay factors and required activities.

Further, the estimation of duration, contract clauses, and human resources required and used, the terms and conditions of the work sequences and capital expenditures are analyzed.

The planned and actual project completion duration is assessed, and gaps are estimated.

The variation between the planned and performed activities is calculated to estimate work performance.

The effect of variance is calculated in order to figure out the results.

Formal reports are generated to make everything clear and understandable for the involved parties.

Takes Away

Nevertheless, the role of the quantum expert is highly critical in the whole process because the analysis is done to indicate what amount of time is required by the entitled party to recover losses. So, the experts use introspection which needed technical skills and adequate experience.

[claimsconsultancy-blog]

Analysis Of The Factors Responsible For Construction Delays

Construction delays are inevitable, even in the most sophisticated, well planned projects. Schedule overruns in projects may be a result of a single event or a multiple connected events. In an attempt to determine the reasons for these delays and to avoid future errors, the contracting parties may hire professionals to resolve delay related disputes and claims.

Specialists hired to study factors causing these delays, are not only certified professionals in the field, but also have years of experience working for construction projects as delay witnesses. This article lists some factors responsible for schedule overruns that delay experts work with, to determine the actual causes behind the hold up:

1.     Errors In The Contract Document

These errors are brought about due to missing information in the contracts, conflicting information requiring design revisions and the absence of a phasing plan in the bid documents when the project has to be completed in phases.

2.     Delays By Contractor-Controllable Factors

These delays are caused when contractors do not pay much attention to the factors that they could have controlled; Lack of labor force on the construction site, disputes between the contractor and his subcontractors, payment issues and lack of proper planning and project management.

3.     Construction Delays Due To Uncontrollable Factors

These construction delays are due to unpredictable factors that neither the contractor nor any other entity could have controlled. These include factors like strikes by manufacturer’s, vendor’s going bankrupt or out of business and delays due to unpredictable weather conditions like storms and hurricanes that cause hindrances in construction projects.

Other, slightly more complicated factors that the delay experts review in order to determine the causes of delay include:

4.     Delays Due To Owner-Controllable Factors

Factors like changes in the project scope, making certain areas of the construction site inaccessible to the contractors, payment issues and political influence that impacts project performance or progress. These changes may be due to the owner’s negligence of controllable factors.

5.     Incompatibility Of The Project Team

A project team may not be compatible to work on the project together which adds to the reasons for delay. In this case, each party will blame the other for the incompatibility, conflicts and hence the delay.

Delay analysis involves an analysis of the project documents to detect which one of the reasons mentioned above caused the construction delays in the project.

Some other important factors that that need to be determined in order to provide a complete analysis include the following:

Noncritical, Critical And Float

Non critical activities may have a margin for delay inculcated into them however, critical activities do not have that margin of delay and delaying these activities could lead towards delay of the whole project. An important part of the project planning is to determine which activities could be classified as critical and non-critical activities.

Delays; Excusable And Non Excusable

Excusable delays are delays that the contractor cannot be accounted for. However, non-excusable delays are ones that the contractor is accountable for. A revision of the contract is essential in order to classify these delays.

Compensable And Non Compensable Delays

Depending on the terms specified in the contracts, compensable delays can be classified as delays that will be compensated for by the delaying parties in terms of cost of the delay. However, non-compensable delays are those that do not result in any provision of cost by the delaying parties.

Conclusion

Delay analysis is an extensive study which helps determine the causes of delay. Individuals or companies that offer these services have multiple years of trainings, globally recognized certifications, and work experience extending over several years.

Although the immediate benefits of hiring a Delay expert may seem minimal and the costs incurred appear higher, however, in the long run mistakes made in the past projects that contributed towards conflicts and project hold ups can be avoided in the future.

[claimsconsultancy-blog]

Steps To Handle Delay Related Risks In Construction Projects?

Construction is a precarious business not only in the United Arab Emirates but all over the world.

As each project is of a distinct nature, thus it brings new opportunities as well as challenges. And, whenever such delays turn into reality, they are likely to hinder your entire project.

Although the identification and management of delay related risks is a bit complicated process, adequate planning can help in their management. Moreover, you can entrust professional delay expert with the responsibility to adequately evaluate, monitor, and check upon such delays to prevent their aggravation into costly construction claims.

Here we have compiled risk mitigation strategies that start form project inception till the end:

Before The Contract Stage

Here the primary aim is to manage delays beforehand so that their likely impact on the project progress can be minimized.

And, hiring consultants or experts at this phase of project management incorporate unexpected incidents that can cause a likely delay in the projection execution in the project planning.

Thus minimalizes project risks.

Project Planning Phase

In today’s business world, time and budgetary constraints hinder project success. Therefore, adequate planning is essential to consider delay mitigation and delay management strategies right from the beginning of the construction process.

Because your project can suffer delay or changes, you need to devise an appropriate plan to reconsider your budget and schedule to accommodate these delays.

Project Execution

During the project execution phase, you have to bring your ideas into the reality. And, whenever, delays occur in the delivery phase of the project, adequate interventions to manage this crisis must be done to turn the plans into reality. Here the role of competent delay expert cannot be ignored.

They professionally manage changes so that they minimally affect the project’s schedule and budget.

Project Appraisal

No one wants to waste time or money in today’s competitive environment. Therefore, it is wise enough to carry out project appraisals from time to time. This will help to let you know your project’s strengths and weaknesses promptly. Although these appraisals are inexpensive interventions, they are highly valuable for managing risks.

Thus, adequate resolution of delays and cost overruns are questionable without employing credible professionals right from project’s beginning.

They help you devise and execute plans that are potentially result oriented and facilitate you in handling delays and disputes associated with them on agreeable terms.

Moreover, involving them in early phase means to avoid these delays into mounting into costly litigations. Thus, consultation can help you save your person-hours and other valuable resources.

Typing it All Together!

Construction projects in the United Arab Emirates are very complex ventures. Likewise, the risks associated with them are also increasingly complicated and are, therefore, difficult to handle

One of the many dangers associated with these ventures is project delays. But, with adequate planning and expertise offered by your construction delay expert you can avoid these delays to ruin your construction project.

[claimsconsultancy-blog]

How To Avoid Weather-Related Delays In Construction?

There is no denying the fact that the industry of construction is highly volatile. It means that no one can precisely estimate the timeline of project completion without considering the associated risks.

The most significant risks are the delays in construction projects, which can occur owing to multifarious reasons. Weather conditions are the one of the most unavoidable. The reason is obvious; no one can predict the same environmental factors throughout the year.

The variability of the weather makes it imperative for the contractors and builders to take adequate measure to restrict such factors from influencing the projects adversely.

Tips to escape weather-related Delays in Construction

However, there is no surely that after complete paperwork and effective implementation of the strategy, the project goes as expected. So, never forget to hire an experienced delay expert prior to any problems or conflict for effective management of the situations.

The article is aimed at offering a number of tips based on essential considerations to escape potential delays related to weather impact:

Consider The Climate Conditions Of The Location

It is the most important factor which is usually overlooked by the builders and contractors. The location of the project can describe a number of factors related to climate.

For instance, if you are going to construct a building in UAE, you can get an in-depth understanding of the seasonal changes from the record of the climate statistics. Generally, the weather of the country is considered dry and hot, but if you look at the records, you will get a better idea when it gets humid.

In this way, you can adjust your timeline to avoid delays in construction potentially.

Follow Weather Predictions

Usually, people think that the construction project is related to architecture, building and MEP but they ignore the factor of weather. So, why they have to see the forecast on a daily basis?

It is because considering weather reports, predictions and forecasts help them to set their workflow accordingly. For instance, they can modify their working hours as per the weather to adjust climate influencers on the construction projects.

Further, assistance from a professionally experienced delay expert can also be a great help in making progressive amendments to the construction plan without annoying anyone.

Divide Construction Projects Into Manageable Modules

An effective way to avoid weather-related postponements is to divide the projects into manageable modules. The decision of constructing different parts of the building should be made in a way that can incorporate climate changes.

For instance, if the weather forecasts show the indication of rain, the inside constructional activities should be performed while in a dry or sunny day, the outside construction work can be accomplished in a manageable way.

FINAL THOUGHT

To sum up, construction is a highly critical process of planning, executing, managing and accomplishing the difference process simultaneously. Therefore, hiring a delay expert from the start of the project can be a right decision taken by the contractors.

Remember! Be a weather forecaster when taking hands in a construction project to avoid potential delays in construction.

[claimsconsultancy-blog]

What Are The Various Types Of Delays In The Construction Projects?

No one wants to delay or postpone their projects, but at times there are situations when there is no way you can actually continue with the project. For successful project management, it is essential to avoid any type of delay which can cost you a project or even decrease the efficiency of the overall project.

There are so many construction projects happening in a row that anything during the process will directly affect the overall revenue and quality of the work. Before the process of avoiding the delays start, it is essential to understand the different types of delay which are existing in the construction industry.

Types Of Delays In The Construction Industry

Following are some types of delay in the construction industry:

Critical And Non-Critical

The very first type of the delay is whether they are critical or not. Critical delays are the one which results in the delay of the entire project. However, non-critical delays are the ones which impact the overall progress of the project but do not push the end deadline. Not all times delays have to be extremely big at times small delay can also hamper the project. Professional delay expert is more likely to decide the critical situation of the delay.

Excusable Delays

There are some unforeseen circumstances which are not in the hand of any human power, so they fall into the category of excusable delay. The delays can be because of any natural disaster or different site conditions such as earth quake or heavy rainfall.

At times the weather conditions are not favorable, or there is a strike going on. The change in the government policy and intervention of the stakeholders can result in small delays. All these things can be excused because the contractor does not have control over it. These delays are not compensable.

Excusable But Compensable Delays

As the name suggests, the delay might be excusable, but the owner has to pay some amount t to the client. The delays’ compensation can be in the form of time extension or in the form of money. The reason can be changes in the instruction or deviation from what has been decided in the initial contract.

Non-Excusable Delays

As it is indicated in the name that delays which are the result of carelessness or inefficiency of the contractors which has pushed the deadline of the project. In some cases, because of an unskilled workforce, some tasks have to redo which is a loss of time.

At this time, the contractor has to work extra hard because there will be no extension in time for the project.

Concurrent Delay

When two different types of delay occur at the same time, then they are known as concurrent delays. The delays might overlap or happen at the same time. At that time the role of delay expert is significant because he or she will check which delay has more impact on the progress of the project.

[claimsconsultancy-blog]

How Can You Avoid Construction Claims?

There is one thing inevitable other than change then it has to be construction industry. It is that one industry that can never go out of business. The number of construction projects and the type of construction projects are increasing every day. There are different departments and different systems involved in one project of construction. Because of its large number of workforces and several other reasons issues arise in these projects are a lot more than anticipated.

The issues or dispute can have a wider range from on-site co-workers disagreements, issues between contractors and work and also issues between contractor and owners. The other issues can be resolved, but issues between contractor and owner can hinder the project progress.

Because of the number of disputes and arguments between the contractors and owner, claims have been filed which can be time or additional cost claims. Construction claims consultants Dubai offers a range of services to analyze the validity of the claim and identify any false claims made.

It is reported that one in every four construction claims has some kind of claims filed. Claims can negatively impact the productivity of the workers, delay the project and hamper the relationship between contractors and the owner.

There are several ways in which you can prevent or avoid the construction claims

Plan The Project Effectively

It is not wrong to say that everything lies in the planning and in the construction industry it is even more important. Planning involves that at each step things are considered carefully, and each risk has been thought off.

It is not possible to measure each and every aspect beforehand but planning the project will enable you to at least foresee all the issues which might come along. It will let you know the works that need to be catered, the number of people required and the budgetary issues.  

Contract Management And Building

Once you have planned the projects and discussed with the possible contractor or the owner, then it is time to write down all you have considered in an official way.

The contract will serve as a type of legal binding where it is essential for you to have a proper understanding of all the clauses. It will also let the both know how they are expected to coordinate with each other.

While building the contract, it is essential for both parties to be on the same page and discussed any conflicts ahead.

Construction claims consultants Dubai not only helps in the analysis of the significant claims but they also provide services during the design and planning phase of the construction projects.

Address the financial risk and responsible party for the risk pre-identified for the project in the contract clauses.

In other words, the contract is signed so that the whole process of the construction project work can be completed in peace.

Hiring The Right Team

This section is more important for a contractor than the owner. But the owner has to be mindful when he or she is employing the contractor. The contractor is the one who will be overseeing and responsible for managing the project.

Therefore, it is essential that owner choose a reputable contractor who has the right knowledge and experience. Contractors spend years to build the reputation with their excellent work, therefore, selecting someone who is reputable in the industry might be a wise choice.

Once the contractor is hired, then it is her or his job to select the workforce as per requirement. A contractor also needs skilled and knowledgeable workforce. Any single thing done wrong by an unskilled worker can impact the outcome of the project.

Hiring people will not happen overnight so when signing the project be mindful of the time which will be required to hire the team for the project. Unskilled workers are going to cost much more if you haven’t spent a reasonable amount of time building up a good time.

Construction claims consultants Dubai are experts in managing the complicated project and provide robust solutions to those projects.

Final Words- Construction industry is growing, and there are going to be issues during the process. However, a reasonable number of issues can be managed by planning the project thoughtfully, documenting the conditions in the form of contract and hiring the right people to work on the project.